PUBLIC LAW 95-563—NOV. 1, 1978
92 STAT. 2389
In case of contumacy or refusal to obey a subpena by a person who resides, is found, or transacts business within the jurisdiction of a United States district court, the court, upon application of the agency board through the Attorney General; or upon application by the board of contract appeals of the Tennessee Valley Authority, shall have jurisdiction to issue the person an order requiring him to appear before the agency board or a member thereof, to produce evidence or to give testimony, or both. Any failure of any such person to obey the order of the court may be punished by the court as a contempt thereof. INTEREST
SEC. 12. Interest on amounts found due contractors on claims shall 41 USC 611. be paid to the contractor from the date the contracting officer receives the claim pursuant to section 6(a) from the contractor until payment thereof. The interest provided for in this section shall be paid at the rate established by the Secretary of the Treasury pursuant to Public Law 92-41 (85 Stat. 97) for the Renegotiation Board. APPROPRIATIONS
SEC. 13. (a) Any judgment against the United States on a claim 41 USC 612., under this Act shall be paid promptly in accordance with the procedures provided by section 1302 of the Act of July 27, 1956, (70 Stat. 694, as amended; 31 U.S.C. 724a). (b) Any monetary award to a contractor by an agency board of contract appeals shall be paid promptly in accordance with the procedures contained in subsection (a) above. (c) Payments made pursuant to subsections (a) and (b) shall be reimbursed to the fund provided by section 1302 of the Act of July 27, 1956, (70 Stat. 694, as amended; 31 U.S.C. 724a) by the agency whose appropriations were used for the contract out of available funds or by obtaining additional appropriations for such purposes. (d)(1) Notwithstanding the provisions of subsection (a) through (c), any judgment against the Tennessee Valley Authority on a claim under this Act shall be paid promptly in accordance with the provisions of section 9(b) of the Tennessee Valley Authority Act of 1933 (16 U.S.C. 831(h)). 16 USC 831h. (2) Notwithstanding the provisions of subsection (a) through (c), any monetary award to a contractor by the board of contract appeals for the Tennessee Valley Authority snail be paid in accordance with the provisions of section 9(b) of the Tennessee Valley Authority Act of 1933 (16 U.S.C. 831(h)). AMENDMENTS AND REPEALS
SEC. 14. (a) The first sentence of section 1346(a)(2) of title 28, United States Code, is amended by inserting before the period a comma and the following: "except that the district courts shall not have jurisdiction of any civil action or claim against the United States founded upon any express or implied contract with the United States or for liquidated or unliquidated damages in cases not sounding in tort which are subject to sections 8(g)(1) and 10(a)(1) of the Contract Disputes Act of 1978". (b) Section 2401(a) of title 28, United States Code, is amended by striking out "Every" at the beginning and inserting in lieu thereof "Except as provided by the Contract Disputes Act of 1978, every".
�
